Sump pump and check valve_Flame.pdf
Ursula Kelley-Wash Petitioner V City Of Oak Park Respondent · 26-002905-TT
Text extracted from the reviewed PDF, organized by page. OCR and reading order may contain errors; confirm details in the PDF below.
Page 1
2200 E. Eleven Mile Road Warren, MI 48091 888-234-2340 BILL TO Ursula Kelly 13101 Northfield Boulevard Oak Park, MI 48237 USA ESTIMATE ESTIMATE DATE 591732024 Jul 03, 2024 J O B A D D R ES S Job: 1055443 Ursula Kelly 13101 Northfield Boulevard Oak Park, MI 48237 USA EST I M AT E D E TA I L S Sump pump and check valve : Replace sump pump with new sump pump and check valve due to float sticking S E RV I C E D ES C R I P T I O N QT Y FLA-566040 Zoeller M53 Cast Iron 1/3 HP Sump Pump: 1.00 Cast Iron Sump Pump replacement- Includes 1.5" Male adapter PVC to attach to an existing check valve FLA-500410 Check Valve Up to 1 1/2" PVC: 1.00 Check Valve Up to 1 1/2" PVC Existing connections Good solution for a failing check valve on your existing sump pump discharge pipe FLA-GDD Gold Plan Diagnostic Discount: 1.00 Diagnostic discount applied to qualifying repairs CUSTOMER AUTHORIZATION I authorize the estimate in the amount of $737.50 Sign here Date Estimate #591732024 Page 1 of 1
Page 2
TERMS AND CONDITIONS 1. All orders not paid for in full in advance are subject to approval by the Company's credit department. 2. This proposal includes all discounts, coupons, and may be withdrawn by the Company if not accepted within 30 (thirty) days. 3. The Company shall carry Workmen's Compensation insurance on all technicians, and $1,000,000 public liability insurance. The Company shall not be liable for damage, loss or delays resulting from fire, explosion, flooding, the elements, labor troubles, or any other cause beyond our control. The Company shall use ordinary care in performing all work, but shall not be liable for incidental or consequential damages, nor shall it be liable for injuries to persons or damage to property expect those directly caused by negligent acts of the Company's employees. 4. Until final payment is made, the Company will retain title to all materials and equipment it installs. 5. Unless noted in this proposal, payment is due in full upon completion of work. A monthly finance charge, equal to the highest allowable interest rate, may be levied on Customer's account if delinquent over 30 days. 6. In the event Customer's account must be referred to attorneys for collection, Customer agrees to pay reasonable attorney fees, court costs and other collections costs. 7. Customer will carry fire, extended coverage and other necessary insurance on their real estate and improvements. Customer shall assume risk of loss or damage to equipment after it is set in place on the job. 8. Every attempt will be made to complete the work on the date(s) specified, but because the Company may have no control over equipment availability and delivery, all completion dates are estimates only. 9. All work, equipment and devices installed as a part of this proposal shall be guaranteed for a period of one (1) year from date of completion of this installation, except as otherwise noted, or in accordance with manufacturer's warranty. THE WARRANTY PERIOD HEREIN IS EXPRESSLY IN LIEU OF ANY OTHER WARRANTIES. THERE ARE NO UNDERSTANDINGS, AGREEMENTS OR PRESENTATIONS, EXPRESSED OR IMPLIED, NOT SPECIFIED BY THIS AGREEMENT AND THIS AGREEMENT CONTAINS THE ENTIRE UNDERSTANDINGS BETWEEN THE PARTIES. THE COMPANY'S LIABILITIES FOR DAMAGES SHALL NOT EXCEED THE CONTRACT PRICE OF THIS CONTRACT. 10. The Company shall not be responsible for any damages incurred due to inability of the building structure to properly support the installed equipment, or for the expense incurred in removing, replacing, or refinishing part of the building structure necessary for the performance of any service or installation, unless otherwise noted in this proposal. 11. The Company shall not be liable for any present or future taxes, charges or other government fees, or any items of equipment, labor or special tests required or recommended by insurance companies, equipment vendors, or governmental authorities. 12. The Company shall not be liable for the identification, detection, abatement, encapsulation, storage, removal, or transportation of any regulated or hazardous substances. Regulated or hazardous substances may include, but are not limited to asbestos, certain refrigerants and refrigerant oils. If any such products or materials are encountered during the course of work, the Company can discontinue work until regulated or hazardous materials have been removed or hazard or liability is eliminated. The Company shall receive an extension equal to the time of delay to complete the work and reserves the right to be compensated for any loss due to a delay.
Page 3
13. This agreement contains the entire understanding between the Company and the Customer. Any modifications, amendments or changes must be in writing and signed by both parties. 14. The Company and the Customer agree that any alteration and deviation from the specifications set forth in the contract agreement including extra costs will be executed only upon written orders and will become an extra charge over and above the estimate. 15. The Customer understands that applicable mechanical, electrical and/or plumbing inspections are their responsibility to schedule. In the event the inspector cannot gain access to the Customer's home, the corresponding re- inspection fee will be the Customer's responsibility. In the event the inspection isn't scheduled, the Customer understands that the benefits that they would have received from the permit and inspection process will be forfeited.